5 formal contract template for decorationFormal contract template for decoration 1Customer (Party A):Organizer (Party B):After friendly negotiation, Party A decided to entr

5 formal contract template for decoration

Formal contract template for decoration 1

Customer (Party A):

Organizer (Party B):

After friendly negotiation, Party A decided to entr

5 formal contract template for decoration

Formal contract template for decoration 1

Customer (Party A):

Organizer (Party B):

After friendly negotiation, Party A decided to entrust Party B to lay floor tiles and wall tiles, and signed this agreement for mutual compliance.

I. Project Location: Room: _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _

Two. Form and structure: _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _

Third, the project:

1, four rooms (two rooms and two halls) shall be paved with 80-80 tiles and corner lines, which shall be flat; A kitchen, a bathroom wall 25-40 porcelain to the top, leaving a ceiling space, grinding corners, the ground 30-30 tiles, required to be flat; The floors of the two balconies should be paved with 30-30 tiles, which should be flat.

2. If no details are involved, Party A shall propose a plan and discuss it.

4. Contracting method: Party A must ensure the materials needed during the decoration period (Party B informs Party A in advance) and the lunch supply during the construction period according to Party B's requirements, and Party B shall be responsible for the construction.

Verb (abbreviation of verb) quality standard: the construction quality meets the safety requirements, and the decoration quality is not lower than the decoration standard of the same construction type, which is recognized by both parties. After the project is completed and accepted, if there are quality problems in Party B's construction within 3 months, Party B shall be responsible for rework and maintenance for free.

Engineering cost of intransitive verbs: materials are provided by Party A, and Party A pays Party B the labor cost of decoration.

Seven. Payment method: In order to ensure the quality of the project, the 500 yuan deposit will be temporarily withheld and returned to Party B in full when there is no problem on. After the project is completed, Party A shall pay Party B the labor cost within three days if it meets the above construction project and design requirements upon acceptance.

Eight. This agreement is made in duplicate, each party holds one copy, which has the same effect. This agreement shall come into force as of the date of signature by both parties.

Party A: Party B:

Signature (seal): Signature (seal):

Tel: Tel:

Year after year, month after month, year after year.

Formal contract template for decoration 2

Employer (Party A): _ _ _ _ _ _ _ _ _ _ _ _ _ _ _

Contractor (Party B): _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _

According to the Contract Law of People's Republic of China (PRC) and relevant laws and regulations, Party A and Party B have reached the following agreement on the interior decoration of the owner's residence on the basis of equality, voluntariness and consensus:

The first decoration content

1, location:

2. Scope of contract:

3. Signing method: Both parties agree to adopt the following methods.

Article 2: Responsibility of both parties

1. Construction started the day after the contract was signed.

2, in strict accordance with the requirements of the employer for construction.

3, the contractor must protect the original bedroom indoor furniture, water, heating, electricity, pipes, etc.

Article 3 about the time limit for a project

1, the term is days, the commencement date is _ _ _ _ _, and the completion date is _ _ _ _.

2. In case of continuous construction, compensate the other party for% liquidated damages.

Article 4 on material requirements

1. Construction can only be started after both parties agree.

This contract is made in duplicate, one for each party. It will take effect after the contract is signed. Automatic failure after completion of construction.

Contractor:

Date: Year Month Day

Employer:

Date: Year Month Day

Formal contract template for decoration 3

Both parties to this contract:

Employer (hereinafter referred to as Party A):

Name:

Address: Room 202, Unit 2, Building 45

Tel:-

Contractor (hereinafter referred to as Party B):

Project leader:

Contact telephone number:

According to the Economic Contract Law of the People's Republic of China and other relevant laws and regulations, on the basis of equality, voluntariness and consensus, Party A and Party B reach the following agreement on matters related to decoration engineering:

1, project location:

2. Project contracting method: contracting for work and materials.

3. The construction period is 30 days.

Commencement date: 20-0 1.05.

Completion date: February 5, 2008

4. Both parties agree that the price of this project is RMB (in words). The down payment is _ _ _ _ yuan, and the second payment is _ _ _ _ yuan.

5. After the project is completed, Party B shall notify Party A for acceptance. Party A shall organize acceptance within two days after receiving the acceptance notice, and fill in the project acceptance form. After the project payment is settled, the handover formalities shall be handled.

6. The warranty period of this project is half a year from the date of acceptance and signature by both parties. After acceptance and signature by both parties, fill in the project warranty.

7. If either party fails to perform the contract or violates national laws and regulations and relevant policies of this Municipality, and is fined or causes losses to the other party, the responsible party shall bear the responsibilities and compensate the losses caused to the other party.

8. If the performance of the contract cannot be continued due to one party's reasons, that party shall promptly notify the other party and go through the contract termination procedures, and the responsible party shall compensate the other party for the corresponding losses.

9. This contract is made in duplicate, one for each party, and shall come into effect after being signed (sealed) by both parties.

Party A:

Date:

Party B:

Date:

Formal contract template for decoration 4

Customer (Party A):

Organizer (Party B):

Engineering project:

Through friendly negotiation between Party A and Party B, Party A decides to entrust Party B to decorate the living room. In order to ensure the smooth progress of the project, this contract (including its annexes and all supplementary contracts) is hereby signed in accordance with relevant national laws and regulations for common compliance.

Article 1: Project Overview

1. Project address: _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _

2, room specifications:

Total: the construction area is _ _ _ _ _ _ _ _ square meters.

3. Construction content: See Annex (1) List of Home Decoration Construction Contents and Construction Drawings for details.

4. Project Commencement Date: _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _

5. Project completion date: _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _

Total days of the project: _ _ _ _ _ _

Article 2: Project Price

The project price (in words) is _ _ _ _ _ _ _ _ Yuan (in words).

Article 3: Quality Requirements

1. The varieties, specifications and names of the main materials used in the project shall be approved by both parties. See Annex (III) List of Final Accounts of Home Decoration Engineering Materials for details.

2. Regarding the acceptance standard of this project, both parties agree to refer to Zhejiang local standard "Acceptance Standard for Residential Decoration".

3. In the process of construction, if Party A has special construction projects or special quality requirements, both parties shall sign a supplementary contract for the increased cost.

Article 4: Method of Payment

1. After the contract is signed, Party A shall pay 100% of the project cost and 50% of the project cost; When the progress of the construction period is over half (year, month and day), Party A will pay 40% of the project payment for the second time. The remaining 10% shall be paid to Party A after the project is completed and accepted. (Note: Construction costs include labor costs)

Party A pays off the project price, and Party B issues a unified invoice, handles the handover to Party A, and issues a decoration project warranty card.

Party A's failure to pay on time is a breach of contract, and Party B has the right to stop the construction. If the project price is not settled after acceptance, it shall not be delivered for use.

2. If there is any increase or decrease in the project or need to be changed during the project construction, both parties shall sign a supplementary contract, and Party B shall issue a construction change form and notify the person in charge of the construction site. Increase or decrease the project price and settle on the spot.

3. If Party A fails to prepay the project price within the time limit stipulated in this contract, Party A shall pay 1% of the unpaid project price to Party B for each day overdue.

4. If Party A mortgages the house decoration to the bank, it shall hand over the mortgage certificate and relevant documents (copies) to Party B. ..

Article 5: Liability for breach of contract

After the contract comes into effect, during the performance of the contract, the party that terminates the contract without authorization shall pay the other party 5% of the total contract amount as liquidated damages. If the actual loss caused to the other party by the unauthorized termination of the contract exceeds the liquidated damages, it shall be compensated.

Article 6: Modification and Termination of the Contract

1. After this contract comes into effect after being signed by both parties, both parties must strictly abide by it. If either party needs to change the contents of the contract, it shall sign a supplementary agreement after both parties reach an agreement through consultation. If it is necessary to terminate the contract, the party who proposes to terminate the contract shall do so in writing, and pay a penalty of 65,438+00% of the total contract price, and go through the termination procedures.

2. In the process of construction, if either party proposes to terminate the contract, it shall submit it to the other party in written form. After both parties agree to go through liquidation procedures and conclude an agreement to terminate the contract, the contract shall be deemed to be terminated.

Article 7: Entry into force of the contract

1. This contract shall be sealed by both parties and come into force after being signed.

2. This contract is made in duplicate, one for each party and the witness department.

Party A (Owner): (Signature) Party B: (Signature)

Tel: Tel:

Date of signing:

Formal contract template for decoration 5

Party A (Owner): ID number:

Party B (contractor): ID number:

Through friendly negotiation between Party A and Party B, Party A decides to entrust Party B to decorate the living room. In order to ensure the smooth progress of the project, according to the relevant national laws and regulations, this contract is specially signed for mutual compliance.

Article 1: Project Overview

1, project address:

2, room specifications: room hygiene

3. Building area: square meters

4. Contracting method: (engineering and material contracting, cleaning and partial contracting)

5. Total price: RMB, in words:

Article 2: Construction Period

1, total duration: days

2. Commencement date of the project: YY.

3. Project completion date: YY, MM, DD, YY.

4. If the completion is delayed due to Party B's reasons, Party A shall pay 1% of the working expenses as liquidated damages every day until the working expenses are deducted. If the completion is delayed due to Party A's reasons, Party B shall be paid 65438+ 0% of the labor cost in the decoration project price for each day of delay.

5. If the unqualified materials and equipment selected by Party A affect the project quality and time limit for a project, Party A shall bear the cost of rework, and Party B shall bear the cost of rework for quality accidents caused by Party B's construction, with the time limit unchanged.

6. During the construction, if the work is stopped due to the project quality problem and the two sides disagree, they will not be punished for delaying the work or the construction period. Both sides should take the initiative to ask the relevant departments to mediate or the arbitration department to coordinate and deal with it, and resolve the dispute as soon as possible to continue the construction.

7. In the process of construction, if it is necessary to rework due to Party A's reasons, or if the construction period is delayed due to Party A's change of construction contents, it is necessary to apply for a visa, and Party A shall bear all the construction costs. If rework is caused by Party B, Party B shall bear the responsibility, and the construction period will remain unchanged.

8. During the construction process, Party A shall be responsible for the quality problems and time delay caused by notifying the construction personnel to change the construction content without Party B's consent.

Article 3: Project Price

The price specified in the schedule "Decoration Project Price List" shall prevail.

Article 4: Quality Requirements

1. The varieties, specifications and names of the main materials used in the project shall be approved by both parties.

2. Regarding the acceptance standard of this project, both parties agree to refer to the local municipal standard DB3 1/T30- 1999 Acceptance Standard for Residential Decoration.

3. In the process of construction, if Party A has special construction projects or special quality requirements, both parties shall sign a supplementary contract for the increased cost.

4. Municipal Family Decoration Professional Committee.

5. The quality of all materials and equipment purchased by Party A shall be borne by Party A; Party B shall be responsible for the quality of the project.

6. If Party A hires a project supervisor, it shall notify Party B before the project starts, so as to facilitate the work connection.

Article 5: Obligations of Party A

1. Party A must provide the house plan and water, electricity and gas circuit diagram approved by the property management department, or Party A shall provide the house plan and water, electricity and gas circuit diagram, and make on-site disclosure to Party B. ..

2. The second decoration project, all or part of the empty house, remove obstacles that affect the construction. Yes, only a part can be vacant.

Furniture, furnishings, etc. Necessary protective measures shall be taken when staying in the house, and Party B shall go through the formalities, and the expenses shall be borne by Party B..

3. If it is really necessary to dismantle or change the original building structure or equipment and pipelines, it shall go through the formalities with the local housing management department and bear the relevant expenses. If you need to use public parts temporarily during construction, you should say hello to the neighborhood.

Article 6: Obligations of Party B

1. Party B shall show its business license on its own initiative.

2. Assign (name) as the on-site representative of Party B, be responsible for the performance of the contract, organize the construction according to the requirements of the contract, and complete the construction task on time with good quality and quantity.

3. Strictly perform the contract and implement the credit period. If the completion is delayed due to out-of-production, slowdown or excuses to induce Party A to pay in advance, it shall be regarded as a breach of contract after investigation.

4. Responsible for the warranty within the scope of decoration construction. The warranty period is 12 months, counting from the date when the project is completed and accepted by Party A. ..

Article 7: Supply of Materials

1. Party B shall clearly price the materials used in this contract in strict accordance with the relevant national price regulations. The materials provided by Party A shall be used in the decoration project specified in this contract, and shall not be used for other purposes without Party A's consent ... If Party B uses them for other purposes, Party B shall compensate Party A at double the price of the misappropriated materials.

2. If the materials and equipment provided by Party B do not meet the quality requirements or have different specifications, they shall be prohibited from being used. If it has been used, all losses caused to the project shall be borne by Party B. ..

3. Party A is responsible for purchasing the supplied materials and equipment and supplying them to the site on time. Delayed arrival, postponed construction period and delayed punishment. Pay Party B 10% of the total materials provided by Party A as the management fee. Party B shall be responsible for the custody, and Party B shall be responsible for the compensation for the losses caused by improper custody.

Article 8: Project Acceptance

1, project quality acceptance, except for concealed works, which need to be accepted by sections, Party B shall organize Party A to conduct completion acceptance after all projects are completed. Both parties shall handle the project settlement and handover procedures.

2. After Party B notifies Party A to carry out process acceptance and completion acceptance, Party A shall come for acceptance within three days. Failing to do so within the time limit, Party A shall be deemed to have voluntarily waived its rights and passed the acceptance. If there is any problem, Party A shall be responsible for it. Party A's own occupancy is deemed as qualified.

3. If Party A fails to come for acceptance within the time specified by Party B, it shall notify Party B in time and set another date. However, Party A shall acknowledge the completion date of the process or project, and bear Party B's storage fee and related expenses.

Article 9: Method of Payment

1. After signing the contract, Party A shall pay 30% of the total amount as the down payment; When the progress of the construction period is over half (year, month and day), Party A will pay 50% of the project payment for the second time; The remaining 20% shall be paid to Party A for settlement after the project is completed and accepted.

2. During the construction of the project, if there is any increase or decrease in the project or need to be changed, both parties shall sign a supplementary contract, and Party B shall be responsible for issuing a construction change report and notifying the person in charge of the construction site. Increase or decrease the project price and settle on the spot.

Article 10: Liability for breach of contract

Article 1 1: dispute settlement

1. In case of any dispute during the performance of this contract, both parties shall settle it through negotiation without affecting the project progress. Or bring this contract and the unified invoice issued by Party B to complain to the Home Decoration Professional Committee of the Interior Decoration Industry Association of the city and demand settlement.

2. The parties are unwilling to settle the dispute through negotiation or mediation, or if negotiation or mediation fails, they may apply to the Arbitration Commission for arbitration according to this contract; -the people's court brought a lawsuit.

Article 12: Modification and Termination of the Contract

2. In the process of construction, if either party proposes to terminate the contract, it shall submit it to the other party in written form, and both parties agree to go through liquidation procedures. After concluding an agreement to terminate the contract, the contract shall be deemed to be terminated.

Article 13: Entry into force of the contract

1. This contract and its annexes shall be sealed by both parties and come into force after being signed.

2. The supplementary contract has the same legal effect as this contract.

3. This contract is made in duplicate, with each party holding one copy.

Party A: (signature) Party B: (signature)

Address of domicile: address of enterprise:

Telephone number:

Year after year, month after month, year after year.

Five related articles on formal contract template for decoration:

★ Five templates of formal contract for house decoration

★ The latest five models from renovation contract.

★ Five model contracts for all-inclusive house decoration.