Contract Commitment Letter 1 20xx July 1 day, the company signed a mechanical equipment lease contract for xx project with XX Co., Ltd. (contract number:). According to the contract, the total construction period is 18 months, the commencement date is 20xx July 1, and the completion date is 20xx June 65438. However, due to the expiration of the contract time, our company voluntarily terminated the contract.
1. During the performance of the Mechanical Equipment Lease Contract, XX Co., Ltd. did not default on any money and expenses payable to our company, nor did it default on the wages of migrant workers.
Two, after the termination of the mechanical equipment lease contract, both parties shall not bear any liability for breach of contract, compensation and compensation.
3. Our company promises to pay the wages of migrant workers on time during the project construction, without default or safety accidents. From the date of signing this letter of commitment (i.e. 20x65438+1October 2 1), any dispute about the construction of xx project has nothing to do with XX Co., Ltd.
Contract Commitment Letter 2 How to determine the legal effect of the commitment letter that the laborer does not sign the labor contract?
Case introduction
Sun and 20xx went to work in a company on June+10 in 5438, with a monthly salary of 1200 yuan and a labor contract commitment letter. During Sun's work, the company signed a written labor contract with him every month and did not apply for social insurance. 20xx65438+1On October 20th, Sun resigned on the grounds that the company failed to handle social insurance according to law, and left the company on the 25th of the same month. In March of 20xx, Sun submitted an arbitration application to the Labor Dispute Arbitration Committee, demanding that Company A pay twice the salary from February of 20xx to February+February of 65438. During the trial, a company issued a statement written by Sun on April/Kloc-0, 20xx, indicating that a company had informed Sun to sign a labor contract and issued the text of the labor contract, but was unwilling to sign a written labor contract with the company because of Sun's reasons. Sun recognized the truth of this statement. Based on this, a company requested to reject Sun's arbitration request on the grounds that Sun did not sign a labor contract and did not meet the requirements of paying double wages.
Focus of controversy
Workers voluntarily reach a promise with the employer not to sign a labor contract. Should the employer pay double wages?
Analysis:
One view is that Article 82 of the Labor Contract Law stipulates that "if the employer fails to conclude a written labor contract with the employee for more than one month but less than one year from the date of employment, it shall pay the employee twice the monthly labor remuneration", emphasizing that the employer should take the initiative to conclude a labor contract with the employee. When the employer has fulfilled the relevant procedures for concluding a labor contract and failed to conclude a labor contract due to the laborer's own reasons, it cannot be simply considered that the employer has not fulfilled its obligations to conclude a labor contract and the fault lies with the laborer. Therefore, Sun's arbitration request is not supported.
The author believes that Sun's arbitration request should be supported. The reasons are as follows: First of all, according to Article 82 of the Labor Contract Law, the employer's obligation to conclude a written labor contract, so the unit should take the initiative to conclude a written labor contract with the employee, including expressing the intention to sign a labor contract to the employee, providing the text of the labor contract, and consulting with the employee. Secondly, the law does not emphasize the reasons and faults of not signing a labor contract, and does not distinguish who does not sign a labor contract. As long as there is no written labor contract, the employer should pay the laborer double wages according to the regulations. Finally, Article 5 of the Regulations on the Implementation of the Labor Contract Law stipulates: "If a laborer refuses to conclude a written labor contract with the employer within one month from the date of employment, the employer shall notify the employee in writing to terminate the labor relationship and not pay the employee economic compensation." . In this case, the employer did not terminate the labor relationship with Sun, but evaded legal responsibility according to Sun's "statement". It can be seen that the law does not consider the situation that workers do not conclude labor contracts. This provision gives the employer the right to unilaterally terminate the labor relationship with the employee without paying compensation when the employee does not conclude a labor contract. Therefore, the employer shall exercise the right to terminate labor relations according to law. When the employer fails to exercise this right, it shall bear corresponding responsibilities for the adverse consequences of labor relations under the labor contract.
Commitment 3 of this contract signed a material supply and labor subcontracting construction contract (hereinafter referred to as the contract) with the Sicilian Project Department of Chongqing Jian 'an Construction Group Co., Ltd. on the condition that he was fully familiar with and understood "JN- 1- 1" and the design content and construction technology of the construction drawing, and was able to complete the construction task with good quality and quantity. In order to abide by the contract, prevent and put an end to all kinds of disputes in construction, and realize the dual goals of "ensuring qualified projects, creating excellent projects" and "safety projects", we make the following commitments:
1, we fully accept the terms and regulations of the contract, strictly abide by and perform our responsibilities, rights and interests stipulated in the contract, and complete the construction tasks within the contracted scope with good quality and quantity.
2. Establish construction management organization and construction management system, and provide professional construction management personnel (such as project leader, builder, technical director, etc.). ) and full-time security officer. Establish the target responsibility system for quality, safety and progress, and be responsible for the quality and safety of construction projects.
3, according to the engineering design drawings and technical standards for construction, not to cut corners, not to cheat; In accordance with the engineering design requirements, construction technical standards and the contract, the building materials, building components and equipment shall be inspected, and the unqualified ones shall not be used.
4. All kinds of auxiliary materials (equipment) needed in the construction should have product certificates, and the installation and use of auxiliary equipment should comply with the safety management regulations (such as the special construction scheme for the installation and removal of hanging baskets). And strictly implement the safety operation procedures.
5. All the construction personnel used have received safety education and technical operation training, and the operators of special jobs have corresponding technical qualification certificates.
6, consciously accept the supervision of the project department, supervision, owners, supervision units (people) and all sectors of society on the construction. Unconditionally accept and implement the construction instructions and arrangements of the project department.
7, establish and improve the construction quality inspection system, strict process management, completes the concealed engineering quality inspection and data.
8. In case of any quality and safety accidents during construction, we will take full responsibility.
9. Perform quality warranty obligations.
If we fail to abide by the contract and this letter of commitment, fail to complete the construction task with good quality and safety according to the requirements of the project department and the construction progress, or stop work for one day without reason, any dispute with the project department during the construction process will be regarded as our breach of contract. We promise to unconditionally accept all our liabilities for breach of contract in this contract, all losses caused thereby and legal investigation by the project department, and at the same time, we automatically give up all the right of interpretation and statement in this contract and this undertaking.
After signing this letter of commitment, our legal responsibilities will take effect immediately.
xxx
Commitment letter of contract 4 commitment letter
To: The xx project undertaken by our company has signed a construction contract with the former villagers' committee of Cheng Nan Street in Yongjia County, under the condition that our company is fully familiar with and understands the design content and construction technology of the construction drawing, and has the ability to complete the construction task with good quality, quantity and safety on schedule. In order to abide by the contract and prevent and eliminate all kinds of disputes in construction, we make the following commitments:
1, we accept the terms and regulations of the construction contract, strictly abide by and perform our responsibilities, rights and interests stipulated in the construction contract, and complete the construction tasks within the contracted scope with good quality and quantity.
2. Establish construction management organization and construction management system, and provide professional construction management personnel (such as project leader, builder, technical director, etc.). ) and full-time security officer. Establish the target responsibility system for quality, safety and progress, and be responsible for the quality and safety of construction projects.
3, according to the engineering design drawings and technical standards for construction, not to cut corners, not to cheat; In accordance with the engineering design requirements, construction technical standards and the contract, the building materials, building components and equipment shall be inspected, and the unqualified ones shall not be used.
4. All kinds of auxiliary materials (equipment) needed in the construction should have product certificates, and the installation and use of auxiliary equipment should comply with the safety management regulations (such as the special construction plan for the installation and removal of lifting machinery). And strictly implement the safety operation procedures.
5. All the construction personnel used have received safety education and technical operation training, and the operators of special jobs have corresponding technical qualification certificates.
6, consciously accept the supervision of the project department, supervision, owners, supervision units (people) and all sectors of society on the construction. Unconditionally accept and implement the construction instructions and arrangements of the project department.
7, establish and improve the construction quality inspection system, strict process management, completes the concealed engineering quality inspection and data.
8. In case of any quality and safety accidents during construction, we will take full responsibility.
9. Perform quality warranty obligations.
If we fail to abide by the provisions of the construction contract and this letter of commitment, fail to complete the construction task with good quality and quantity and safely according to the requirements of the project department and the construction progress plan, or stop work for one day without reason, any dispute with the project department during the construction process will be regarded as our breach of contract. We promise to unconditionally accept all our liabilities for breach of contract in this contract, all losses caused thereby and legal investigation by the project department, and at the same time, we automatically give up all the right of interpretation and statement in this contract and this undertaking. After signing this letter of commitment, our legal responsibilities will take effect immediately.
Commitment unit (official seal):
Legal person or representative of the commitment unit (signature):
ID number:
Commitment location:
Commitment time: year month day
Contract Commitment Letter 5 In view of the land transfer contract signed by Party A and Party B on March 1 20xx, in order to ensure the normal production of Party B, Party A promises as follows:
1. Party A must provide the site for Party B to produce cement barrels before May 10 of Gregorian calendar.
2. Party A must ensure that the vegetable fields in Party B's production area are plowed before May 20 10 of Gregorian calendar 20xx.
3. Party A must be completed before May 20xx 10; Mechanized roads in Party B's production area.
4. Before May 30th, 20xx, Party A must lay the supervisor of sprinkler irrigation facilities required by Party B's production, and ensure water supply, and the responsible materials must be in place.
5. Party A must build Party B's house for production and living before June 20xx of Gregorian calendar, and ensure water and electricity supply.
6. Party A must buy a new medium-sized truck before August 20xx of Gregorian calendar.
This letter of commitment shall come into effect as of the date of signature by Party A and have the same legal effect as this contract. If Party A fails to fulfill the above commitments on schedule, it shall compensate Party B for economic losses of 400,000 yuan.
Commitment:
date month year
Contract Commitment Letter 6 If our company is lucky enough to win the bid, Nantong Huayuan Technology Development Co., Ltd. has no objection to the contract terms in the bidding documents of the intelligent system project for the overall relocation of Hai 'an Fire Building, and responds in full accordance with these terms.
Authorized representative of the bidder as a legal person: (signature)
Bidder (seal):
Date:
Contract Commitment Letter 7 Party A: X City X Property Management Co., Ltd.
Party B:
Rule number one. In accordance with the Labor Law of People's Republic of China (PRC) and the company's rules and regulations that do not conflict with the local laws and regulations of Guangdong Province and X City, both parties sign this letter of commitment on the basis of equality, voluntariness and consensus.
Second, the training commitment period
This commitment expires within three years from the date of signing.
Article 3. Pay training fees
1. Training fee refers to the fee with payment voucher, including travel expenses incurred during training.
2. During the contract period, all expenses incurred by Party A in providing various trainings for Party B shall be paid by Party A. ..
3. Pay the training fee for the termination of the contract
1) Where Party B proposes to terminate the labor contract, it shall make equal contribution during this commitment period, and pay in descending order according to the service years that the employee has performed;
2) If Party B violates Party A's rules and regulations or has poor performance during the work period, and Party A proposes to terminate the labor contract, it shall be paid in equal amount according to the investment amount during the commitment period, and shall be paid gradually according to the service years that the employees have performed;
3) Party A proposes to terminate the labor contract due to force majeure (for example, the enterprise needs to lay off employees due to economic reasons, etc.). ), Party B does not need to pay the training fee;
4) After the expiration of this commitment, Party A shall not require Party B to pay the training fee;
Article 4. Fulfill the training obligation
1. After receiving the training, Party B shall submit the documents and training materials obtained during the training to the relevant departments of Party A for archiving;
2. Party B shall submit the original and photocopy of the training certificate to the relevant departments of Party A for the record;
3. Party B shall timely convey the knowledge learned during the training to relevant personnel of Party A;
Article 5. Any dispute between Party A and Party B during the performance of this commitment shall be settled on the principle of mutual consultation. If there are unresolved disputes, you can apply to the enterprise labor dispute mediation committee for mediation, or you can apply to the labor dispute arbitration committee for arbitration.
Article 6. Matters not covered in this letter of commitment shall be implemented in accordance with relevant state regulations.
Article 7. If the terms of this letter of commitment conflict with the provisions promulgated by the state in the future, the new provisions of the state shall prevail.
Article 8. This commitment has legal effect as soon as it is made according to law, and both parties must strictly perform it.
Article 9. This letter of commitment is made in duplicate, one for each party, with the same legal effect.
Party A: X City X Property Management Co., Ltd. Party B:
Representative (signature): (signature):
Date: Date:
Commitment letter of contract: Office of XXXX Transaction Management Committee in XX District, XX City:
Both parties to the contract (name of the tenderer) and (name of the winning bidder) make the following commitments on signing the contract (name of the project):
1. Sign the contract in strict accordance with the Contract Law of People's Republic of China (PRC), Construction Law of People's Republic of China (PRC), bidding documents and bidding documents, and follow the principles of equality, voluntariness, fairness, honesty and credibility.
Second, there is no inconsistency between the contents of the contract and the substantive terms of the bidding documents and bidding documents. If the contents of the contract are inconsistent with the bidding documents and the substantive terms of the bidding documents, both parties to the contract will bear all the responsibilities arising therefrom.
Tenderee: _ _ _ _ _ _ _ _ (seal)
Legal Representative: _ _ _ _ _ _ _ _ (signature)
_ _ _ _ _ _ _ _ _ _ _ _ _ _ _
Winning bidder: _ _ _ _ _ _ _ _ (seal)
Legal Representative: _ _ _ _ _ _ _ _ (signature)
_ _ _ _ _ _ _ _ _ _ _ _ _ _ _
Contract Commitment Letter 9 xxxxx Company:
Our company solemnly promises that the xxx contract (ContractNo.: xxxxx) signed by our company and xxxxx company on xxxxx project is required by our company to be signed by xxxxx company, which is only used by our company in XXXXX. This contract is not used as the basis for settlement between the two parties. There is no business or economic exchange between our company and XXXXX company related to this contract, so our company has no right to require XXXXX company to undertake any economic responsibility and other responsibilities with this contract. The actual business of both parties shall be subject to the contract signed separately by both parties. Hereby promise!
Commitment: (official seal)
Legal Representative: (Signature)
Xx year xx month xx day
Contract Commitment Letter 10 Once our company is recommended as the candidate for winning the bid, our company will negotiate the construction contract with the tenderee in accordance with the Model Text of Construction Contract for Construction Projects (GF- 1999-020 1) promulgated by the State Administration for Industry and Commerce and the Ministry of Construction. Our company promises the main terms of its contract.
If our company does not accept the main terms of the following contract, the tenderer has the right to choose the second and third candidates.
First, the project acceptance
The project completion acceptance shall be carried out according to the acceptance method stipulated by the state.
Second, the construction period
The bidding period is 120 days. If the construction period is delayed due to the reasons of the construction unit, the construction period will not be postponed, and Party A shall bear all the economic losses caused thereby. Due to the tight construction period of this project, except for force majeure and Party A's reasons, the construction period will not be postponed. Our company has fully considered various factors affecting the construction period, including rainy season construction and power outage measures. The cost of not taking measures to catch up with work. If the construction period is delayed due to our company's reasons, the construction period will not be postponed, and for each day of delay, it will bear the penalty of Wu Bai yuan; Party A shall also bear all economic losses caused by the delay of the construction period, and the maximum compensation amount of liquidated damages for the construction period shall not exceed 10% of the total contract price.
Third, the project quality
Ensure that the project quality meets the acceptance standards stipulated in the relevant documents of this project. If the project quality fails to meet the standards stipulated in the tender due to our company's reasons, our company should rework in time, bear the rework fee, delay the construction period, and bear the economic liquidated damages of 2% of the contract price; If the project is reworked due to the reasons of the construction unit, the construction unit shall bear the cost of rework, and the construction period shall be postponed accordingly.
Fourth, the project price and payment
1, the contract price is guaranteed at one time according to the bid quotation promised by the winning bidder, and the adjustment of the contract price is implemented according to the relevant provisions of this tender document.
2. Pay an advance payment of 20% of the total project price within 15 days after the contract is signed and started.
3. After deducting the down payment of 20%, the remaining project funds will be allocated according to 80% of the actual project progress of the month. The project payment for design change shall be adjusted and paid according to the proportion of progress payment in the same period, and payment shall be stopped after 80% of the total cost of the completed project is paid. After the completion of the project meets the specified quality requirements, the remaining balance except the quality guarantee fund shall be paid within 30 days.
4, after the completion of the project settlement, leave 5% as the project warranty.
5. The warranty money expires according to the regulations of the Ministry of Construction, and will be refunded after earnestly performing the warranty duties, without interest.
6. Adjustment of contract price: It shall be implemented according to Article 7 of Chapter II.
Verb (abbreviation for verb) project subcontracting
In order to ensure the quality of the project, our company shall not subcontract or link the project. The specific construction technology and materials must be approved by the construction unit when subcontracting, and meet the requirements of various building regulations. The builder must be a registered builder of the unit.
The construction department and all management personnel of the project construction must be consistent with the personnel in the tender and always be in the corresponding posts. Otherwise, Party A may terminate the contract, and Party B has no right to return the bid bond and bear all the losses caused to Party A ... When the construction personnel in charge of this project go out due to special circumstances during the project implementation, they need to obtain the consent of the owner.
Six, safety in production
In the process of construction, our company should ensure safe production and civilized construction. In case of major construction accidents or casualties, all responsibilities and expenses shall be borne by Party B. ..
Seven. Breach of contract and compensation
Breach of contract and claim for compensation according to Articles 35 and 36 of General Terms and Conditions of Model Construction Contract for Construction Projects (GD- 1999-020 1).
1. No matter whether Party A or Party B is uneasy about performing the obligations under this contract, they shall be liable for breach of contract.
2. Party B's failure to fulfill the bidding promise, changing the construction engineer and technical director without authorization, subcontracting the project or subcontracting the project without Party A's consent are regarded as breach of contract, and Party A has the right to terminate the contract and all the economic consequences caused thereby.
All losses shall be borne by Party B. ..
Eight. Mediation and arbitration of contract disputes
If there are any problems in the execution of this contract, both parties shall refer to the Contract Law of People's Republic of China (PRC) and solve them in a spirit of mutual understanding and mutual accommodation. When necessary, it may be submitted to the higher authorities of both parties for mediation. In case of dispute, it shall be arbitrated by the relevant departments or submitted to the people's court with jurisdiction for adjudication.
Nine. Supplementary, Effective and Invalid Contract
For matters not covered in this contract, both parties can supplement and modify it through consultation, and the supplementary contract has the same effect as this contract.
This contract shall come into effect after being signed, sealed and notarized by both parties, and shall naturally become invalid from the effective date to the completion of project acceptance and delivery, and after the bond debt is settled.
Bidder: legal representative or entrusted agent of Yunnan Yongyao Construction Engineering Co., Ltd. (company seal): (signature)
20xx April 10
Commitment letter of contract11_ _ _ _ _ _ Company:
Our company solemnly promises as follows: _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _. _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ Hereby promise!
Commitment: _ _ _ _ _ _ (official seal)
Legal Representative: _ _ _ _ _ _ (signature)
_ _ _ _ _ _ _ _ _ _ _ _ _ _ _
Letter of Contract Commitment 12 to: Company
Our company signed a contract with your company on July 26th, 20xx (hereinafter referred to as the contract).
In order to strengthen the construction of a clean government in business activities, prevent all kinds of illegal and disciplinary actions to seek illegitimate interests, standardize the behaviors of both parties to the contract, ensure the smooth and fair business order, and protect the legitimate rights and interests of both parties, according to the Contract Law of People's Republic of China (PRC) and the General Principles of Civil Law, our company promises the following clean government responsibilities:
Article 1 The Company promises to follow the principles of voluntariness, fairness, compensation for equal value, honesty and credibility in its business dealings with your company, and ensure that the principles of openness, fairness, justice, honesty and transparency are adhered to in the process of contract conclusion and performance (unless otherwise stipulated by laws, regulations or contract documents), and the interests of the state, the collective and your company will not be harmed in order to obtain illegitimate interests.
Article 2 The Company guarantees that the Company and its staff maintain normal business dealings with your company, conduct business activities in accordance with the provisions and procedures of relevant laws and regulations, and abide by the following provisions:
1, without any reason.
Providing or giving gifts, securities, valuables, kickbacks, tips, thank-you fees, etc. To your employees.
2. There is no reason.
Reimbursement of expenses that should be paid by your employees.
3, don't accept or dark
It is convenient for your staff to decorate the house, get married, arrange spouse and children to work, go abroad and travel.
4. Not for your company.
Workers provide communication tools, transportation tools, high-grade office supplies and other materials.
5. There is no reason.
Organize banquets, fitness and entertainment activities for employees that may affect integrity and fairness.
6. Don't promise afterwards
Pay benefits to your employees.
7. Do not provide other improper benefits to your staff in other ways.
8. The illegitimate interests mentioned in the above clauses include but are not limited to money and goods. Such as kickbacks, commissions, shares, shareholder qualifications, bonds, promotion fees, sponsorship fees, advertising fees, labor fees, red envelopes, gifts, membership cards with money, token cards (vouchers), travel expenses, employment opportunities, project opportunities, various high-end daily necessities, luxury consumer goods, handicrafts, collectibles, houses, vehicles, debt relief, guarantees and free.
Article 3 Our company agrees that if you violate the above agreement, you have the right to terminate the contract, and the relevant responsibilities shall be borne by our company; Suspected of committing a crime, your company has the right to hand it over to judicial organs for criminal responsibility. If this causes economic losses to your company, we agree to compensate.
Commitment party (seal):
Authorized representative:
Date:
Commitment Letter of Contract 13 Commitment Party:
ID number:
Address:
Telephone:
Commitment party:
Address:
Telephone:
Guarantor:
Address:
Telephone:
_ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ refers to any one of _ _ _ _ _ _ _ _ _
1. The promisor shall unconditionally perform the responsibilities, rights and interests of Party B in the labor subcontracting contract.
2, engineering quality, safety, wages of migrant workers, the progress of the project and other issues by _ _ _ _ _ _ _ _ labor subcontracting company to bear the responsibilities and losses (including indirect losses) are unconditionally borne by the promisor.
3. Abide by relevant national laws, regulations, standards, new policies and relevant systems of labor service companies.
4. Accept the management and supervision of relevant departments, general contracting enterprises and labor service companies.
5. Shall not damage the image and reputation of the labor service company and other things that are detrimental to the labor service company.
6. Labor workers (including special workers) to whom Party B belongs shall apply for accident insurance and hold relevant certificates when entering the site, and other social insurance shall be handled in accordance with relevant regulations.
7. If losses and accidents are caused by Party B's responsibility during the construction, they must be solved as soon as possible according to relevant regulations, otherwise, the labor service company has the right to detain all creditor's rights and other private property in the general contracting enterprise through various means (including judicial means) to solve them.
8. This commitment contract was signed on _ _ _ _ _ _ _ _ _.
9. All taxes, fees and management fees caused by the above-mentioned contract to the _ _ _ _ _ _ labor subcontracting company and other problems caused by the above-mentioned contract (the above-mentioned clauses) shall be unconditionally borne by the promisor.
Commitment (signature):
_ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _
Commitment party (signature):
_ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _
Guarantor (signature):
_ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _
Contract Commitment Letter 14 Xinjiang Xunjitong Human Resources Service Center (Co., Ltd.) In order to ensure the smooth implementation of the bidding project, we solemnly make the following commitments:
1. We declare that there are no acts of lending (leasing) enterprise qualifications, collusion and fraud in the bidding activities of this project, and offenders will bear corresponding economic and legal responsibilities.
2. Our company pays taxes according to law, is in good financial condition, and has no bad records such as being ordered to suspend business, take over property, freeze or go bankrupt.
3. Since the establishment of our company in 20xx, there have been no bad behaviors such as bid fraud and serious breach of contract, and there have been no lawsuits.
4. Our company has a good social reputation, and has a good reputation and credibility in the financial industry, health and hygiene, fire safety and labor disputes.
5. We promise that the project leader and management personnel will go to the site for management according to the agreed time, and the equipment and consumables will enter the site on time.
6. We promise to strictly fulfill the requirements of the contract and relevant technical specifications, ensure the quality of engineering services, run through safety skills training and strictly control safety management, so as to reassure Party A and employees.
7. We promise to strictly enforce the laws and disciplines of building a clean government and fighting corruption, and put an end to illegal acts.
8. Commitment to establish a wage payment system, put an end to malicious unpaid wages, and put an end to petitions; Otherwise, they are willing to bear economic and legal responsibilities.
9. Our company guarantees that the listed documents and materials are true and effective; 100% commitment has been implemented.
10. Provide general VAT invoice or special VAT invoice (deductible).
15 Letter of Commitment to Contract: Beijing XXXXXX Co., Ltd.
My unit solemnly promises that the project signed with Beijing XXXXXX Co., Ltd. on, month and day, the contract content is: the contract amount is:. We hereby apply for termination of this contract.
Our company promises that after the termination of the above-mentioned contract, we will no longer apply for materials payment from your company, and all losses caused thereby will be borne by our unit.
Commitment unit (full name, official seal):
date month year